GUESSING AS TO YOUR CONSTRUCTION DAMAGES IS NOT THE BEST APPROACH

Posted on August 24, 2019August 24, 2019 by Edward Garber

Arbitrarily guessing as to your construction damages is NOT the best approach. Sure, experts can be costly. No doubt about it. Having an expert versus guessing as to your construction damages caused by another party’s breach of contract is a no brainer. Engage an expert or, at a minimum, be in a position to competently testify as to your damages caused by another party’s breach of contract. Otherwise, the guessing is not going to get you very far as a concrete subcontractor found out in Patrick Concrete Constructors, Inc. v. Layne Christensen Co., 2018 WL 6528485 (W.D. New York 2018) where the subcontractor could not competently support its delay-related damages or change orders and, equally important, could not support that the damages were proximately caused by the general contractor’s breach of the subcontract.

In this case, the concrete subcontractor entered into a subcontract to perform concrete work for a public project. The project was delayed and the general contractor was required to pay liquidated damages to the owner. Not surprisingly, the subcontractor disputed liability for delays and sued the general contractor for all of its delay-related damages “in the form of labor and materials escalation, loss of productivity, procurement and impact costs, field and home office overhead, idle equipment, inability to take on other work, lost profits, and interest.” Patrick Concrete Constructors, 2018 WL at *1.

The general contractor moved for summary judgment as to the plaintiff’s delay-related damages – the subcontractor’s damages were nothing but guesses and the subcontractor could not prove the general contractor was the cause of the subcontractor’s damages.

The portion of the deposition transcript of the subcontractor’s president that may have also been its corporate representative as to damages is telling:

Q: After today’s exercise, do you believe you’re entitled to [$]681,740 under those items [regarding change orders]?

A: No.

Q: What amount [are] you entitled to?

A: I don’t know. I’d have to work it up.

Q: So as of right now, with my one chance to depose you, the person on damages, you can’t give me a figure that you’re actually entitled to?

A: No. We just ripped all these figures apart, so now I got to go back and refigure.

With regard to the amount of damages sought for “extra costs,” Bell [the President of subcontractor] testified as follows:

Q: Okay. Then you have – you total everything here, total of everything except for the Amount Due on Contract and Outstanding Change Order heading. So that [$]915[,000] basically added up everything under Extra Costs Not Submitted all the way down to Extra Equipment?

A: Yes.

Q: You’re asking for [$]915[,000] in this. Do you believe that’s actually what you’re entitled to today?

A: Well, like I said, we were – like you said, we have to do some adjustments here.

Q: Okay. Adjustments downward, correct, sir?

A: Yes.

Q: Can you tell me today what you think you’re actually entitled to?

A: No.

And, there was more. The subcontractor could not locate its original estimate for the job, which is important for any loss of productivity or inefficiency claim – or any claim dealing with added labor and equipment usage. The subcontractor could not identify payroll records, time cards, vendor invoices, or anything to justify the damages it sought. The subcontractor guessed as to labor hours without the back-up substantiating the labor hours and, equally important, could not establish it incurred the guesstimated labor hours caused by the general contractor.

In essence, Plaintiff [subcontractor] concedes that it cannot provide the Court with an “intelligent estimate without speculation or conjecture,” for either category of damages. Because Plaintiff has failed to make a factual showing sufficient to establish that the “extra costs” and “change orders” damages are capable of being proved with reasonable certainty, summary judgment dismissing these claims is appropriate.

***

Here, Plaintiff asserts that Defendant [general contractor] breached the Subcontract by delaying the Project, and that Defendant’s delay caused it to sustain damages. However, Plaintiff has admitted that Defendant was not responsible for all of the delay, and that Plaintiff and its reinforcing bar subcontractor contributed to the delay as well. Because, by Plaintiff’s own admission, it contributed to the damage-causing delays, it is required to allocate the amount of delay and resultant damages between, at a minimum, itself and Defendant.

Patrick Concrete Constructors, 2018 WL at *4.

Please contact David Adelstein at dadelstein@gmail.com or (954) 361-4720 if you have questions or would like more information regarding this article. You can follow David Adelstein on Twitter @DavidAdelstein1.

USING THE YARDSTICK TEST TO PROVE LOST PROFIT DAMAGES

Posted on May 22, 2015November 8, 2024 by Edward Garber

It’s all about proving your damages! One category of consequential damages that parties sometimes seek is lost profit damages. Lost profits, though, are one of the most difficult damages to prove. If a party is interested in pursuing lost profit damages (such as when the opposing party materially breaches their contract) it is important to understand the burden and expert testimony needed to support these damages with a reasonable degree of certainty.

In a prior article, I discussed a tenant supporting a lost profit claim against its landlord due to the landlord’s breach of the lease. Recently, in Victoriana Buildings, LLC v. Ft. Lauderdale Surgical Center, LLC, 40 Fla.L.Weekly D1169b (Fla. 4^th DCA 2015), the Fourth District found that a tenant did not properly support its lost profit damages even though the landlord breached the lease. The Court affirmed that the tenant’s lost profits claim was speculative and, therefore, not recoverable. In reaching this determination, the Court explained:

Lost profits are typically proven by one of two methods: (1) the before and after theory; or (2) the yardstick test. The yardstick test is generally used when a business has not been established long enough to compile an earnings record that would sufficiently demonstrate lost profits and compares the profits of businesses that are closely comparable to the plaintiff’s. Here, the tenant’s expert consultant, in analyzing the viability of the tenant’s proposed facility, did not evaluate any comparable facility’s profitability as a “yardstick,” and the tenant’s expert CPA acknowledged that his report, which was based on the consultant’s report and forecast, was only as good or as bad as [the consultant’s] forecast. Thus, the tenant’s proof was insufficient.

Victoriana Buildings, supra (internal quotation and citation omitted).

Without a true proven history of profitability, the tenant should have used the yardstick test supported by sufficient expert testimony. Under this yardstick test, the expert would analyze closely comparable businesses to render an opinion as to the lost profits caused by the defendant’s breach. Because the tenant’s expert failed to properly perform this yardstick analysis, the tenant was denied lost profit damages since these damages became purely conjectural.

If you have incurred damages, it is important to consult with counsel to ensure the damages you have incurred can be sufficiently proven. Whether those damages are lost profit damages or another category of damages, it is crucial to sufficiently prove these damages in accordance with applicable law. Otherwise, you can wind up in the position of not properly presenting your damages at trial. In the case of a business that does not have a sufficient track record to prove lost profitability, a yardstick needs to be established to prove lost profits with a reasonable degree of certainty.

WAIVER OF CONSEQUENTIAL DAMAGES AND LOSS OF USE DAMAGES (IN CONSTRUCTION / DESIGN DEFECT DISPUTE)

Posted on January 24, 2015November 8, 2024 by Edward Garber

In construction / design defect cases, a plaintiff (party proving defect) may assert a category of damages referred to as loss of use damages. Importantly, if your contract includes a waiver of consequential damages, these types of damages will not be recoverable. This is a significant issue to consider when entering into a construction contract, especially when you are the owner of the project, because if you do not want to waive a party you hire of consequential damages (such as loss of use damages), then you do not want to include a waiver of consequential damages in your contract or, at a minimum, you want to carve out exceptions to the waiver of consequential damages. Stated differently, this is an issue and risk you want to consider on the front end because even though construction / design defects are not anticipated, they do occur.

In a construction / design defect scenario, an owner’s consequential damages would generally be those damages unrelated to repairing the defect. For instance, loss of use of the property or lost rental income to an owner during the implementation of the repairs would be a consequential damage that would be waived by a waiver of consequential damages provision in an owner’s contract.

An example of a waiver of consequential damages provision found in the AIA A201 (general conditions of the construction contract between an owner and contractor) is as follows:

The Contractor and Owner waive Claims against each other for consequential damages arising out of or relating to this Contract. This mutual waiver includes

.1 damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons; and

.2 damages incurred by the Contractor for principal office expenses including the compensation of personnel stationed there, for losses of financing, business and reputation, and for loss of profit except anticipated profit arising directly from the Work.

This mutual waiver is applicable, without limitation, to all consequential damages due to either party’s termination in accordance with Article 14. Nothing contained in this Section 15.1.6 shall be deemed to preclude an award of liquidated damages, when applicable, in accordance with the requirements of the Contract Documents.

(See AIA A201-2007, s. 15.1.6)

Now, if loss of use damages are not contractually waived, the recent decision in Gonzalez v. Barrenechea, 40 Fla. L. Weekly D258a (Fla. 3d DCA 2015), illustrates how an owner can recover these types of damages when there is a construction / design defect. In this case, an owner sued its architect for design errors with the HVAC system in a newly constructed home. The owner was forced to engage a new design professional to address the deficiencies. It took the owner 20 months to repair the deficiencies during which the owner claimed he could not live (or use) his new house. Although the owner did not live in the house, there was evidence that the owner had some use of the house. For instance, the owner’s son slept in the house on an intermittent basis, the owner docked his boat at the dock behind the house, furniture was stored in the house, and the owner had cars parked in the garage.

Notwithstanding some use of the house, the owner put on testimony of an expert real estate appraiser that testified that the owner incurred lost rental value of approximately $15,500 per month during the 20-month repair period. The architect argued that this rate was flawed because the expert failed to factor in the use the owner had of the house during the 20-month period. The trial court agreed and denied the owner the loss of use damages.

The Third District Court reversed the trial court finding that the owner was entitled to loss of use damages:

Under Florida law, a homeowner that loses the use of a structure because of delay in its completion is entitled to damages for that lost use. Florida courts have held that “[d]amages for delay in construction are measured by the rental value of the building under construction during the period of delay.”

Gonzalez, supra, quoting Fisher Island Holdings, LLC v. Cohen, 983 So.2d 1203, 1204 (Fla. 3d DCA 2008).

Furthermore, because the architect failed to put on any evidence as to what the rental value of the house should have been during the 20-month period factoring in the owner’s use of the house during this period, there was nothing to refute the owner’s rental rate.

This case touches upon important take-aways:

Consider the risk of a waiver of consequential damages provision on the front end, especially if you are an owner. Likewise, if you are a contractor or design professional, you want to consider the risk of not having such a waiver of consequential damages.
Loss of use damages are recoverable in a construction / design defect case absent a contractual waiver of consequential damages.
An owner can introduce evidence of loss of use damages through an expert real estate appraiser that can testify as to the rental rate of the property during the repair period.
A contractor or design professional defending a loss of use damages claim should engage its own expert to counter an owner’s expert. In this case, if the design professional had an expert real estate appraiser, it would have put on evidence of a rental rate much lower than the $15,500 per month factoring in the owner’s limited use of the house during this time period.